| This leads to distrust betweenstakeholders,recourse to the courts, loss of money and delay tobenefitting from the services ofthose projects | So This study aims to identify The causing factors of delay in the service projects,and Shed light on the most important factors and putting the solutions to improve the Execution ofprojects with the least delays possible |
|---|---|
| Followed by a statistics, being carried out as frequently as each of delaying factors, Thetenmost frequent factors in the delay of Municipality projects were : Delayed arrival of thefinancial allocations, The bureaucracy and restrictive regulations, Additional statements andchange orders, Crossing of infrastructure services, Weakness of contractor's competence,Ineffective planning and scheduling, Shortage of labors in thework site, The procedures takenwhen the Contractor is delay such as Warning and drawing work, Public holidays and occasionsand closing of the roads, Encroachments |
To achieve the objectives of this study, a Case Studymethod has been adopted in a sample of Karbala Municipality's projects to get the required dataand information, and used File — Maker programto facilitate the collection and organization ofdata.
7.
1.
27